Code Civ. Proc., § 529.2 · Chapter 3. Injunction
Code Civ. Proc., § 529.2
Text — As published in the Legislative Counsel's database, tables dated October 18, 2026 (pubinfo_2025.zip)
(a) In all civil actions, including, but not limited to, actions brought pursuant to Section 21167 of the Public Resources Code, brought by any plaintiff to challenge a housing project which is a development project, as defined by Section 65928 of the Government Code, and which meets or exceeds the requirements for low- or moderate-income housing as set forth in Section 65915 of the Government Code, a defendant may, if the bringing of the action or the seeking by the plaintiff of particular relief including, but not limited to, injunctions, has the effect of preventing or delaying the project from being carried out, apply to the court by noticed motion for an order requiring the plaintiff to furnish an undertaking as security for costs and any damages that may be incurred by the defendant by the conclusion of the action or proceeding as the result of a delay in carrying out the development project. The motion shall be made on the grounds that the action is without merit and that the action was brought in bad faith, vexatiously, for the purpose of delay, or to thwart the low- or moderate-income nature of the housing development project.
(b) In responding to a motion for undertaking, the plaintiff may seek to limit the amount of the undertaking by presenting admissible evidence that filing an undertaking will cause it, and in cases where the plaintiff is an unincorporated association, its members, to suffer undue economic hardship. If the court, after hearing, determines that the grounds for the motion have been established, the court shall order that the plaintiff file the undertaking in an amount specified in the court’s order, taking into consideration any admitted evidence of plaintiff’s economic hardship and avoiding causing the plaintiff to suffer undue economic hardship, as security for costs and damages of the defendant. The liability of the plaintiff pursuant to this section for the costs and damages of the defendant shall not exceed five hundred thousand dollars ($500,000). If the court concludes, based on all of the admissible evidence presented, that a bond in any amount would cause the plaintiff undue economic hardship, the court is authorized in its discretion to decline to impose a bond.
(c) If at any time after the plaintiff has filed an undertaking the housing development plan is changed by the developer in bad faith so that it fails to meet or exceed the requirements for low- or moderate-income housing as set forth in Section 65915 of the Government Code, the developer shall be liable to the plaintiff for the cost of obtaining the undertaking.
Notes and commentary — not statutory text
History
Amended by Stats. 2024, Ch. 285, Sec. 1. (SB 393) Effective January 1, 2025.
Source of truth
- Edition
- As published in the Legislative Counsel's database, tables dated October 18, 2026 (pubinfo_2025.zip)
- Official file
- https://leginfo.legislature.ca.gov/faces/codes_displaySection.xhtml?lawCode=CCP§ionNum=529.2.
- Text hash
- sha256 c96d52d70c02a1569564e9d80a18367c4ec41ba7a9048780afd27670e272f817
- Composed by
- compose_ca.py 2026-10-22: the Legislative Counsel's CAML content files read by a tokenizer (caml_readers.reader_a); an independent xml.etree reading (caml_readers.reader_b) agrees on every section
This section cites
Provisions in this library that the text above cites, as it prints each citation. A range cited as “ss. 61.13-61.16” links its first and last provisions.
Cited by 1 provision
Provisions in this library whose text cites Code Civ. Proc., § 529.2. Each shows the citation as that text prints it.
Procedural information only. Not legal advice and not a substitute for the advice of an attorney. Confirm the current text with the official publisher before relying on it.